Terms of Service
Last updated: October 17, 2026
Agreement to Terms
By accessing and using snap-windows.com (the "Website") and our quote request services, you agree to be bound by these Terms of Service ("Terms"). If you do not agree to these Terms, please do not use our Website or services.
About SNAP Windows
Company Name: SNAP Windows LLC
Licensed Contractor: David Vasquez
License Holder: HCC Group LLC
SNAP Windows LLC operates using a licensed contractor. All work is performed under the qualifying license of David Vasquez through HCC Group LLC. We are fully insured with General Liability and Workers' Compensation coverage.
Quote Request Service
No-Obligation Estimates
Quote requests submitted through our Website are free and non-binding. A quote is an estimate based on the information and photos you provide. It is not a final contract or commitment from either party.
Quote Accuracy
We strive to provide accurate estimates based on your photos and project details. However, final pricing may change after an in-person site visit, inspection, or discovery of unforeseen conditions (e.g., structural issues, code violations, or material availability).
Quote Validity & Pricing
Quotes are valid for 14 days from the date issued.
Due to manufacturer price fluctuations, pricing is subject to change. If a quote is accepted after a price increase has occurred, updated pricing may apply.
User Responsibilities
When using our Website and services, you agree to:
- Provide accurate, complete, and truthful information
- Upload clear, recent photos of the windows and doors for which you are requesting a quote
- Respond promptly to our communications regarding your quote
- Not upload inappropriate, copyrighted, or unlawful content
- Not use our services for any fraudulent or illegal purpose
General Contracting Services
Licensed & Insured
Snap Windows operates as a licensed General Contractor in the State of Florida (CGC1524851) and maintains General Liability and Workers' Compensation insurance for all projects.
Permits and Inspections
All impact window and door installations require building permits in Florida. We handle the permitting process, including application, fees, and coordination with local building departments. Final inspections are required by law before project completion.
Code Compliance
All installations are performed in accordance with the Florida Building Code (FBC) and High-Velocity Hurricane Zone (HVHZ) standards. We ensure compliance with local codes, manufacturer specifications, and industry best practices.
HOA Requirements
If your property is governed by a Homeowners Association (HOA), you are responsible for obtaining HOA approval prior to installation. We can provide documentation and specifications to assist with your HOA application.
Limitation of Liability
Important Disclaimer
TO THE MAXIMUM EXTENT PERMITTED BY LAW, SNAP WINDOWS SHALL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, OR PUNITIVE DAMAGES ARISING FROM YOUR USE OF OUR WEBSITE OR SERVICES.
Our liability is limited to:
- Website availability and functionality issues
- Errors in quotes or estimates (correctable before contract signing)
- Delays in quote preparation or communication
- Third-party service failures (email, SMS, cloud storage)
For contracted installation work, separate liability terms will be outlined in your signed construction agreement.
Payment Terms
Payment terms for contracted work are as follows:
- 50% of materials due at contract signing (plus permit processing fee)
- 50% of materials due prior to delivery
- 50% of installation cost due prior to installation
- 50% of installation cost due upon completion
Payment Methods
Accepted payment methods include check, Zelle, and credit/debit cards.
- Check and Zelle payments have no processing fee
- Credit/debit card payments are subject to a 3.5% administrative fee
Intellectual Property
All content on this Website, including text, graphics, logos, and software, is the property of Snap Windows or its licensors and is protected by copyright and intellectual property laws.
Photos you upload remain your property. By uploading photos, you grant us a limited license to use them for quote preparation and project management purposes only.
Third-Party Services
Our Website may utilize third-party services such as CRM systems, communication tools, payment processors, cloud storage, and analytics platforms.
We are not responsible for the availability, accuracy, or policies of these third-party services.
Termination
We reserve the right to refuse service, suspend access, or terminate your use of our Website at our sole discretion for any reason, including violation of these Terms or fraudulent activity.
Governing Law
These Terms are governed by the laws of the State of Florida, without regard to its conflict of law provisions. Any disputes arising from these Terms or our services shall be resolved in the courts of Florida.
Changes to These Terms
We may update these Terms from time to time. Changes will be posted on this page with an updated "Last Updated" date. Your continued use of our Website after changes constitutes acceptance of the revised Terms.
Severability
If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.
Contact Information
If you have questions about these Terms of Service, please contact us:
Snap Windows
Licensed General Contractor: CGC1524851
Email: quotes@snap-windows.com
Serving: Miami-Dade, Broward, and Palm Beach Counties, Florida